Apex Interior Linings (“we”, “us”, or “our”)
Welcome to our website. These Terms and Conditions (“Terms”) govern the provision of interior lining, plastering, and related trade services, as well as quotes, orders, and the use of our website. By requesting a quote, engaging our services, or browsing our website, you (“Client”, “you”) agree to be bound by these Terms and applicable Queensland and Australian laws.
1. Quotes and Acceptance
Validity: Unless otherwise specified in writing, quotes provided by Apex Interior Linings remain valid for 30 calendar days from the date of issue.
Acceptance: A quote is accepted, and a binding contract formed, when you accept the quote in writing, pay a required deposit, or authorize us to commence work on site.
Variations: Any changes, additions, or structural variations to the original scope of work requested by the client or necessitated by site conditions will be quoted separately and added to the final contract price.
2. Pricing and Payment
Currency: All prices are quoted in Australian Dollars (AUD) and are exclusive of Goods and Services Tax (GST) unless explicitly stated otherwise.
Payment Terms: Payment must be made in accordance with the payment schedule set out in our quote or invoice. Default terms for non-account clients are payment upon milestone completion or completion of works.
Trade Accounts: Approved trade account holders must settle accounts within the agreed credit terms (e.g., 30 days from invoice date).
Queensland Security of Payment: Progress payments and claims are made pursuant to the Building Industry Fairness (Security of Payment) Act 2017 (Qld). Failure to pay on time may result in interest charges, suspension of works, or legal recovery action.
3. Site Access and Work Conditions
Access: The Client must provide clear, safe, and uninterrupted access to the site for our personnel, vehicles, equipment, and sub-contractors during agreed working hours.
Preparation: The Client must ensure the site is structurally sound, clear of debris, and adequately prepared (e.g., framing straight and ready for lining) prior to our commencement, unless site preparation forms part of our agreed scope.
Delays: Delays caused by lack of site access, unready preceding trades, or unsafe site conditions may incur additional costs or extend completion timeframes.
4. Defects and Workmanship Guarantee
Standards: All plastering and lining work will be carried out in a professional, workmanlike manner in accordance with the National Construction Code (NCC) and relevant Australian Standards (including AS/NZS 2589 for gypsum linings).
Inspection & Notification: The Client must inspect the work upon completion and notify us in writing of any defects, omissions, or quality concerns within 7 calendar days.
Rectification: Where valid defects exist due to faulty workmanship or materials provided by us, Apex Interior Linings will rectify the issues within a reasonable timeframe at no additional charge.
5. Consumer Guarantees & Limitation of Liability
Australian Consumer Law: Our services come with guarantees that cannot be excluded under the Australian Consumer Law (ACL) set out in Schedule 2 of the Competition and Consumer Act 2010 (Cth).
Exclusions: To the maximum extent permitted by law, we are not liable for:
Pre-existing structural defects, frame movement, or building settlement causing cracks in plaster or linings.
Damage caused by third-party trades, water leaks, severe weather, or client misuse after installation.
Indirect, consequential, or economic loss arising from project delays.
6. Risk and Retention of Title
Risk: Risk in materials delivered to the site passes to the Client upon delivery.
Ownership: Ownership of all materials and supply items remains with Apex Interior Linings until all invoices relating to the project are paid in full. We reserve the right to enter the site and retrieve materials if payment is in default.
7. Intellectual Property & Website Use
Website Content: All text, imagery, logos, architectural details, and project photos displayed on our website are the property of Apex Interior Linings and protected by intellectual property laws.
Designs & Plans: Custom designs, shop drawings, or technical specifications prepared by us remain our intellectual property and must not be used without written consent.
8. Workplace Health and Safety (WHS)
Apex Interior Linings complies with the Work Health and Safety Act 2011 (Qld). We reserve the right to suspend or refuse work in any area deemed unsafe under Queensland safety regulations.
9. Governing Law
These Terms are governed by and construed in accordance with the laws of Queensland, Australia. Both parties submit to the exclusive jurisdiction of the courts of Queensland.
10. Contact Information
For questions regarding these Terms and Conditions or to contact management:
Business Name: Apex Interior Linings
Email: [Insert Contact Email]
Phone: [Insert Contact Phone Number]
Address: [Insert Business Address, Queensland, Australia]
Last updated: September 2026
